BS
Boise Standard
Treasure Valley · AI Directory
48 C.F.R. · Federal Acquisition Regulations System
48 C.F.R. § 42.1302

Suspension of work.

Title 48 C.F.R. ● ACTIVE Primary Source
Regulatory Text

48 C.F.R. § 42.1302 — Suspension of work.

Federal Acquisition Regulations System 1 2023-10-01 2023-10-01 false Suspension of work. 42.1302 Section 42.1302 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION CONTRACT MANAGEMENT CONTRACT ADMINISTRATION AND AUDIT SERVICES Suspension of Work, Stop-Work Orders, and Government Delay of Work 42.1302 Suspension of work. A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.

Source: ecfr.gov · govinfo.gov — public domain Official Source ↗
Root-LD Entity Data
◈ Machine-Readable Provenance Record Root-LD v1.0 · boisestandard.org
Federation ID
BS-CFR48-SEC-384F9E
Entity Class
REGULATION / FEDERAL-CFR-SECTION
Domain Signature
boisestandard.org
Citation
48 C.F.R. § 42.1302
Corpus
CFR — Code of Federal Regulations
Status
✓ ACTIVE
Source
PRIMARY-SOURCE
Source Verified
✓ TRUE
Content Hash
5b10bf9b915d2fc1...
Semantic Edges
Pending — corpus passes queued
The regulatory text of 48 C.F.R. § 42.1302 is reproduced from the official Code of Federal Regulations as published by the Office of the Federal Register and the National Archives and Records Administration.
Navigate Corpus — Title 48 C.F.R.
← 48 C.F.R. § 42.1301 48 C.F.R. § 42.1303 →
Title 48 — Federal Acquisition Regulations System
48 C.F.R. § 1.00048 C.F.R. § 1.10148 C.F.R. § 1.10248 C.F.R. § 1.102.148 C.F.R. § 1.102.248 C.F.R. § 1.102.348 C.F.R. § 1.102.448 C.F.R. § 1.102.548 C.F.R. § 1.10348 C.F.R. § 1.10448 C.F.R. § 1.10548 C.F.R. § 1.105.148 C.F.R. § 1.105.248 C.F.R. § 1.105.348 C.F.R. § 1.10648 C.F.R. § 1.10748 C.F.R. § 1.10848 C.F.R. § 1.10948 C.F.R. § 1.11048 C.F.R. § 1.20148 C.F.R. § 1.201.148 C.F.R. § 1.201.248 C.F.R. § 1.20248 C.F.R. § 1.30148 C.F.R. § 1.30248 C.F.R. § 1.30348 C.F.R. § 1.30448 C.F.R. § 1.40048 C.F.R. § 1.40148 C.F.R. § 1.402
48 C.F.R. — public domain ← All Legislation
◈ Provenance
boisestandard.org → United States → Law → CFR → Title 48 → 48 C.F.R. § 42.1302